The Press-Dispatch
Issue link: https://www.ifoldsflip.com/i/1135273
B-8 Classifieds Wednesday, June 26, 2019 The Press-Dispatch NOTICE TO BIDDERS GENERAL Notice is hereby given that separate sealed bids will be received by the City of Petersburg, Indiana until 4:00 pm local eastern time on July 15, 2019 at the Petersburg City Hall, 704 E. Main Street, Petersburg, Indiana 47567 for the following work: Partial Clearance, Removal of Environmental Conditions and Support of facade and support of adjacent building walls 606/608 Main Street, Petersburg, Indiana 47567 Bids received aer this time will be returned unopened. Each Bid must be enclosed in a sealed envelope bearing the title "Petersburg Clearance Project" and the name and address of Bidder. Lump Sum Bids will be received from General Contractors for the project as shown on the Drawings and hereinaer specified and as set forth on the Contractors Bid Form to be constructed in one single prime contract. Contractors sealed Bid Packages shall include the following properly executed documents submitted in triplicate: Indiana State Board of Accounts Form 96 (Parts I & II) Part III - Base And Alternate Bids Part IV - Subcontractor Listing Form Contractor's Qualification Statement Bid Guarantee Bids will be opened and publicly read aloud at the Petersburg City Hall, 704 E. Main Street, Petersburg, Indiana 47567 at July 15, 2019 at 6:30 pm local time. All interested citizens are invited to attend and should any citizens require special provisions, such as handicapped modifications or non-English translation personnel, such provisions will be provided if requested seven days prior to the bid opening. Copies of the Contract Documents are on file and open to public inspection at the following locations during regular office hours: City of Petersburg, Town Hall, 704 East Main Street, Petersburg, Indiana 47567 Architectural Design Concepts, LLC, 415 Clay Street, Suite A, Jasper, IN 47546 McGraw Hill Construction / Dodge, 8900 Keystone Crossing, 540, Indianapolis, IN 46240 Builders Exchange of Louisville, 2300 Meadow Drive, Louisville, KY 40218 Reed Construction Data, Document Processing Center, 30 Technology Pkwy S, Ste 100, Norcross, GA Electronic files of the Contract Documents may be reviewed and purchased at the following location: Repro Graphix, Inc., 14 N.W. 6th. Street, Evansville, Indiana 47708, (812) 422-2400, upon a non refundable payment of $150.00 (One hundred and fiy dollars) for each set. If paying by check, please make checks payable to Architectural Design Concepts, LLC. If mailing is required, mail cost shall be paid for by the Contractor. A CD may be purchased by bidders that have purchased a complete set of bidding documents for a non refundable payment of $40.00 (Forty dollars). Documents may also be ordered at (www.reprographix.com). e Owner has completed an Environmental Site Assessment on the Property. Findings and conclusions of all of the reports completed, regarding asbestos inspection and lead-base paint inspection are contained in the assessments and can be downloaded from Repro Graphix, Inc. at (www. reprographix.com). e work for which bids are requested includes all labor, materials, equipment and items of materials and services required to provide the proper and complete construction of this project. e work shall be constructed in accordance with this Notice to Bidders, Project Manual, Drawings and Addenda, as prepared for this project. Each bidder is responsible for inspecting the Project site and for reading and being thoroughly familiar with the contract documents and specifications. e failure or omission of any Bidder to do any of the foregoing shall in no way relieve any Bidder from any obligation with respect to its Bid. e work to be performed and the bid to be submitted shall include sufficient and proper sums for the structure partial demolition, waste management, and certified disposal, labor, materials, permits, licenses, insurance, and so forth incidental to and required. Bid and Bid Guarantees shall be placed in sealed envelopes and addressed to the Owner, the City of Petersburg, and shall list the name and address of the Bidder. Should any Bidder withdraw his bid or bids within 90 (Ninety) days aer the time of Bid Opening or if issued a Letter of Intent, withdraw his bid or bids aer the issuance of such Letter of Intent, or fail to execute a Form of Agreement if presented, the Owner may declare the Bid bonds forfeited to the Owner as liquidated damages. e Owner reserves the right to (1) accept any bids by a Letter of Intent within 90 (Ninety) days aer the time of Bid Opening and a presentation of a Form of Agreement within 90 (Ninety) days from the date of such Letter of Intent (2) at any time reject all bids and (3) waive all informalities, irregularities, or errors in the bidding, provided it is not in violation of the Notice to Bidders or the Statutes of the State of Indiana. A conditional or qualified bid will not be accepted. Bidders not issued a Letter of Intent will have their Bid Guarantees returned within seven (7) days aer the issuance of the Letter of Intent. Bid Guarantee: Each bid shall be accompanied by a certified check, cashier's check, money order or a satisfactory bid bond executed by the bidder and an acceptable surety, payable to the City of Petersburg, in an amount equal to 5% of the maximum bid. e attorney-in-fact who executes the Bond on behalf of the Surety shall affix to the Bond a certified and current copy of his Power-of-Attorney. Bids shall be executed on Indiana State Board of Accounts Form No. 96 with Non-Collusion Affidavit, with all sections completely filled in and sworn to as required by the Statutes of Indiana for all bids. All prices quoted, are to be free of all Federal Excise Taxes and State Sales Tax, and upon request of supplier, tax exemption certificate will be executed by the Owner to the successful bidder to cover all items subject to this tax. Contractors receiving awards shall furnish an approved Performance Bond, Labor and Material Payment Bond for 100% of the contract which shall be in full force and effect for 12 months from date of acceptance of work. Bonds shall be furnished at time of written notice to proceed with the work. A Pre-bid conference will be held at the Petersburg City Hall, 704 E. Main Street, Petersburg, Indiana at July 2, 2019 at 10:30 am local time. All prime contractors, subcontractors, small, minority or women owned enterprises and other interested parties are encouraged to attend. Representatives of the Owner and Architect will be present to discuss the project. e building will be open for review on that day. Questions concerning the contract documents or bidding procedures shall be directed to the following: Architectural Design Concepts, LLC., 415 Clay Street, Suite A, Jasper, Indiana 47546 - David A. Henson - adchenson@twc.com e Contractor shall submit with his bid a completed Contractor's Qualification Statement, AIA Document A305. e Owner reserves the right to reject each and every bid, and to waive informalities, irregularities, and errors in the bidding to the extent permitted by Law. is includes the right to extend the date and time for receipt of bids. e City of Petersburg encourages the Contractor, Subcontractors, Vendors, etc. to make every effort to utilize the residents of Pike County as suppliers for equipment, materials, and work force whenever possible. Award will be made to the low, responsive, responsible bidder. e low, responsive, responsible bidder must not be debarred, suspended, or otherwise be excluded from or ineligible for participation in federally assisted programs under Executive Order 12549. All applicable laws, ordinances, and the rules and regulations of all authorities having jurisdiction over construction of the project shall apply to the project throughout. Davis Bacon Wage rates do not apply to the project. Bidders on this work shall be required to comply with the provisions of the President's Executive Order No. 11246, as amended. e Bidders shall also comply with the requirements of 41 CFR Part 60 - 4 entitled Construction Contractors - Affirmative Action Requirements. A copy of 41 CFR Part 60 - 4 may be found in the Supplemental General Conditions of the Contract Documents and Specifications. e Bidders attention is also called to the "Minority/Women Business Participation" requirements contained in the Project Specifications. e Indiana Office of Community and Rural Affairs has adopted a State goal of 10% participation for minority and women owned businesses for construction related or purchase related contracts for the work. e Contractor must meet guidelines and practices established by the Indiana Office of Community and Rural Affairs and appropriate federal regulations including: 1) Executive Order 11246, 2) Section 3 of the Housing and Community Development Act of 1968, as amended, 3) Certification of Non-Segregated Facilities, 4) OMB Circular A-102, 5) Title VI of the Civil Rights Act of 1964, 6) Section 504, Rehabilitation Act of 1973, 7) Age Discrimination Act of 1975, 8) Executive Order 12138, 9) Conflict of Interest Clause, 10) Retention and Custodial Requirements for Records Clause, 11) Contractors and Subcontractors Certifications, and others that may be appropriate or necessary. Contract procurement is subject to the federal regulations contained in the OMB Circular A-102, Sections B and O and the State of Indiana requirements contained in IC-36-1-9 and IC-36-1- 12. Any contract(s) awarded under this Advertisement for Bids are expected to be funded in part by a grant from the Department of Housing and Urban Development, as administered by the Indiana Office of Community and Rural Affairs. Neither the United States nor any of its departments, agencies or employees is or will be a party to this Advertisement for Bids or any resulting contract. Mayor R.C. Klipsch City of Petersburg (June 19, 26, 2019) hspaxlp 63-19-0017-SS PIKE COUNTY SHERIFF'S OFFICE TO THE OWNERS OF THE WITHIN DESCRIBED REAL ESTATE AND ALL INTERESTED PARTIES NOTICE OF SHERIFF SALE Sheriff 's file No.: 63-19-0017-SS Date & Time of Sale: Wednesday, July 31, 2019 at 10:00 a.m. Location of Sale: Pike County Sheriff 's Office, Basement. Judgment to be satisfied: $75,280.22 Cause Number: 63C01-1812-MF-000366 Plaintiff: U.S. BANK NATIONAL ASSOCIATION, AS TRUSTEE FOR BAYVIEW FINANCIAL MORTGAGE PASS-THROUGH TRUST 2006-B Defendant: JEREMY B. HELSLEY By virtue of a certified copy of a decree to me, directed from the Clerk of Superior/Circuit Court of Pike County Indiana, requiring me to make the sum as provided for in said DECREE, with interest and cost, I will expose at public sale to the highest bidder at the date, time and location listed above, the fee simple of the whole body of Real Estate, a certain tract or parcel of land described as follows: Part of the Northeast quarter of the Southeast quarter of Section (7) Township (2) South, Range (7) West in Pike County, Indiana, and more particularly described as follows: Beginning at an iron on the North line eleven hundred twenty and no hundredths (1,120.00) feet East of an iron marking the Northwest corner of said quarter quarter section; thence East along said North line two hundred fieen and fiy-six hundredths (215.56) feet to an iron marking the Northeast corner of said quarter quarter section; thence South 01 degrees 02 minutes 30 seconds West along the East line of said quarter quarter section four hundred and no hundredths (400.00) feet to an iron; thence West and parallel to the North line of said quarter quarter section two hundred fieen and sixty-six hundredths (215.66) feet to an iron; thence North 01 degrees 03 minutes 20 seconds East and parallel to the West line if said quarter quarter section four hundred and no hundredths (400.00) feet to an iron at the point of beginning. Together with rents, issues, income and profits thereof, this sale will be made without relief from valuation or appraisement laws. In accordance to the requirements of IC 32-29-7-3, this Notice shall also represent service of Notice of Sale of this real estate upon the owners. Kent Johnson Sheriff of Pike County Township: Patoka Parcel No.: 63-11-07-400-109.000-009 4550 SOUTH COUNTY ROAD 300 EAST, WINSLOW IN 47598 e Sheriff 's Department does not warrant the accuracy of the commonly known address published herein. S Brent Potter, Plaintiff 's Attorney Attorney No. 10900-49 Doyle & Foutty, P.C., Attorney Law Firm 317-264-5000 (June 19, 26 and July 3, 2019) hspaxlp 63-19-0018-SS PIKE COUNTY SHERIFF'S OFFICE TO THE OWNERS OF THE WITHIN DESCRIBED REAL ESTATE AND ALL INTERESTED PARTIES NOTICE OF SHERIFF SALE Sheriff 's file No.: 63-19-0018-SS Date & Time of Sale: Wednesday, July 31, 2019 at 10:00 a.m. Location of Sale: Pike County Sheriff 's Office, Basement. Judgment to be satisfied: $29,932.25 Cause Number: 63C01-1901-MF-000040 Plaintiff: FIFTH THIRD BANK, AN OHIO BANKING CORPORATION SUCCESSOR BY MERGER TO FIFTH THIRD BANK, A MICHIGAN BANKING CORPORATION DOING BUSINESS AS FIFTH THIRD BANK, INDIANA (SOUTHERN) Defendant: PATTY SHERMAN and SANDY MELTON, ELLIE GREEN AND UNKNOWN HEIRS, DEVISEES & LEGATEES OF SHARON K. RUMBLE By virtue of a certified copy of a decree to me, directed from the Clerk of Superior/Circuit Court of Pike County Indiana, requiring me to make the sum as provided for in said DECREE, with interest and cost, I will expose at public sale to the highest bidder at the date, time and location listed above, the fee simple of the whole body of Real Estate, a certain tract or parcel of land described as follows: e following described real estate situate in Pike County, in the State of Indiana, to-wit: A part of the northwest quarter of Section 5, Township I South, Range 9 West, and described as follows: Begin at a point one foot West and 18 1/2 rods south of the northeast corner of the northwest quarter of said section, township and range and running thence west 116 feet; thence north 132 feet; thence east 116 feet; thence south 132 feet to the point of beginning, containing 0.351 acres, more or less. Together with rents, issues, income and profits thereof, this sale will be made without relief from valuation or appraisement laws. In accordance to the requirements of IC 32-29-7-3, this Notice shall also represent service of Notice of Sale of this real estate upon the owners. Kent Johnson Sheriff of Pike County Township: Clay Parcel No.: 63-05-05-501-007-000-001 2965 COUNTY 850 WEST ROAD, HAZLETON IN 47640 e Sheriff 's Department does not warrant the accuracy of the commonly known address published herein. Patricia L Johnson, Plaintiff 's Attorney Attorney No. 23332-15 Gerner & Kearns Co LPA, Attorney Law Firm 513-241-7722 (June 19, 26 and July 3, 2019) hspaxlp 63-19-0019-SS PIKE COUNTY SHERIFF'S OFFICE TO THE OWNERS OF THE WITHIN DESCRIBED REAL ESTATE AND ALL INTERESTED PARTIES NOTICE OF SHERIFF SALE Sheriff 's file No.: 63-19-0019-SS Date & Time of Sale: Wednesday, July 31, 2019 at 10:00 a.m. Location of Sale: Pike County Sheriffs' Office, Basement. Judgment to be satisfied: $44,093.71 Cause Number: 63C01-1810-MF-000310 Plaintiff: CITIBANK, N.A, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY AS OWNER TRUSTEE FOR NEW RESIDENTIAL MORTGAGE LOAN TRUST 2014-3 Defendant: KAREN WHEATLEY, AKA KAREN FAY WHEATLEY By virtue of a certified copy of a decree to me, directed from the Clerk of Superior/Circuit Court of Pike County Indiana, requiring me to make the sum as provided for in said DECREE, with interest and cost, I will expose at public sale to the highest bidder at the date, time and location listed above, the fee simple of the whole body of Real Estate, a certain tract or parcel of land described as follows: A part of the Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, particularly described as follows, to wit: Commencing 5 rods North of the Southeast corner of the Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, and running from thence North 432 feet; thence West 452 feet; thence Southeast 432 feet; thence East 277 feet to the place of beginning, containing 3 1/2 acres more or less. Except: A part of the Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, particularly described as follows, to wit: Beginning at a point 234.50 feet North of the Southeast corner of the above-described Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West; thence West 120 feet; thence North 111.50 feet; thence East 120 feet; thence South 111.50 feet to the place of beginning, containing 5/8 acre, more or less. (is description taken from a former deed executed by Walter Risley and Hattie Risley, husband and wife, to Homer Robling and Gladys Robling, husband and wife, August 29, 1960, and recorded September 24, 1960, in Deed Record 72, Page 207, in the Office of the Recorder of Pike County, Indiana.) Also Except: A part of the Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, particularly described as follows, to wit: Beginning at a point 346 feet North of the Southeast corner of said above-described Northwest Quarter of the Northwest Quarter, Section 32, Township 1 South, Range 7 West; thence West 230 feet; thence North 66 feet; thence West 153 feet to the centerline of State Highway No. 61; thence Northwest with said State Highway No. 61, North 19 degrees and 48 minutes West 121 feet; thence East 452 feet; thence South 168 feet to the place of beginning. (Taken from a former deed executed by Walter Risley and Hattie Risley, his wife, to Homer Robling and Gladys Robling, husband and wife, February 3, 1955, and recorded August 13, 1955, in Deed Record 68, Page 433, in the Office of the Recorder of Pike County, Indiana.) Also Except: A part of the Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, particularly described as follows, to wit: Beginning at an established point on the center line of State Highway No. 61, which said established point is 5 rods North 277 feet West and North 19 degrees 48 minutes West 258 feet from the Southeast corner of the Northwest Quarter of the Northwest Quarter of said Section 32, Township 1 South, Range 7 West, and running from said initial point East 135 feet; thence North 80 feet; thence West 153 feet to the centerline of State Highway No. 61; thence South 19 degrees and 48 minutes East 80 feet to the place of beginning, containing 28/100 of an acre, more or less. (Taken from a former deed executed by Walter Risley and Hattie Risley, his wife, to Julian J. Duncan and Pauline E. Duncan, his wife, executed February 6, 1953, and recorded February 10, 1953, in Deed Record 66, Page 571, in the Office of the Recorded of Pike County, Indiana.) Also Except: A part of the Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, particularly described as follows, to wit: Beginning at a point in the center of State Highway No. 61, which said point is 74.35 feet Northwest of a point in the center of said State Highway No. 61, which latter point is 5 rods North 277 feet West and 19 degrees 45 minutes West, 178 feet from the Southeast corner of the said Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, and running from said initial point East 156.55 feet; thence South 70 feet; thence East 86 feet; thence North 111.50 feet; thence West 245 feet to the center of State Highway No. 61; thence in a Southeasterly direction along and with the meanderings of the center of said State Highway No. 61, 5.65 feet to the place of beginning. (Taken from a former deed executed by Walter Risley and Hattie Risley, his wife, to Homer Robling and Gladys Robling, husband and wife, December 19, 1949, and recorded January 13, 1950, in Deed Record 64, Page 333, in the Office of the Recorder of Pike County, Indiana.) And Also Except: A part of the Northwest Quarter of the Northwest Quarter of Section 32, Township 1 South, Range 7 West, particularly described as follows, to wit: Beginning at a point in the center of State Highway No. 61, which said point is 5 rods North, 277 feet West and 19 degrees 48 minutes West 178 feet from the Southeast corner of the said Northwest Quarter of the Northwest Quarter of said Section 32, Township 1 South, Range 7 West, and running from said initial point East 131.5 feet; thence North 70 feet; thence West 156.55 feet to the center of said State Highway 61; thence along and with the said highway in a Southeasterly direction 74.35 feet to the place of beginning. (Taken from a former deed executed by Walter Risley and Hattie Risley, his wife, to Homer Robling and Gladys Robling, husband and wife, August 4, 1948, recorded September 10, 1948, in Deed Record 63, Page 313, in the Office of the Recorder of Pike County, Indiana.) Together with rents, issues, income and profits thereof, this sale will be made without relief from valuation or appraisement laws. In accordance to the requirements of IC 32-29-7-3, this Notice shall also represent service of Notice of Sale of this real estate upon the owners. Kent Johnson Sheriff of Pike County Township: Patoka Parcel No.: 63-07-32-200-018.000-009 2223 SOUTH STATE ROAD 61, WINSLOW IN 47598 e Sheriff 's Department does not warrant the accuracy of the commonly known address published herein. Elyssa M Meade, Plaintiff 's Attorney Attorney No. 25352-64 Manley Deas Kochalski, LLC, Attorney Law Firm 614-222-4921 (June 19, 26 and July 3, 2019) hspaxlp LEGALS LEGALS LEGALS LEGALS SUDOKU Here's How It Works: Sudoku puzzles are formatted as a 9x9 grid, broken down into nine 3x3 boxes. To solve a sudoku, the numbers 1 through 9 must fill each row, col- umn and box. Each number can appear only once in each row, column and box. You can figure out the order in which the numbers will appear by using the numeric clues already provided in the boxes. The more numbers you name, the easier it gets to solve the puzzle! LEGAL NOTICE OF PUBLIC HEARING e Alcohol Beverage Board of Pike County, Indiana will hold a public hearing at 11:30 am on July 05, 2019 at the County Court House, Basement Auditorium Room, 801 E Main in the city of Petersburg in said county, to investigate the propriety of holding an alcoholic beverage permit by the applicants listed herein to wit: RR6326952 Beer Retailer -Restaurant RENEWAL. No 423 Smokehouse, Inc 804 E Illinois St, Petersburg IN. D/B/A No 423 Smokehouse. Beth Ann Hess 1782 E Private Rd 485 N, Petersburg, Secretary. JOHN RYBURN HESS 1782 E PRIVATE RD 485 N Petersburg, President. (June 26, 2019) hspaxlp